Tag Archive for: Building bond

A Downer of a decision: The importance of articulating adjudication submissions

/in

In Diona Pty Ltd v Downer EDI Works Pty Ltd [2020] NSWSC 480 (Diona), the Supreme Court considered an application to set aside an Adjudicator’s Determination for failure to consider the terms of the contract as required by s 22(2)(b) of the Building and Construction Industry Security of Payment Act 1999 (the SOP Act).

Key takeaway:

  • It is important to ensure that adjudication submissions clearly articulate all relevant arguments and contractual provisions. Unclear, poorly framed or ambiguous submissions can be costly.
  • An adjudicator’s decision will not be declared void simply because it contains what one party considers to be an error or failure by the adjudicator to expressly address all arguments made in parties’ submissions.
  • Lawyers can be useful to assist in preparing an adjudication application and response. Having prepared and responded to numerous security of payment claims, the lawyers at Bradbury Legal are experts at ensuring your arguments are clearly articulated.

 

Background

Diona Pty Ltd (Diona) entered into a subcontract with Downer EDI Works Pty Ltd (Downer), for Downer to provide works in relation to safety upgrades on the Great Western Highway, Blackheath. Downer proceeded to adjudication on a payment claim under the SOP Act. On 16 April 2020, the relevant Adjudicator determined that Downer was entitled to a progress payment of $430,990.13 (Determination).

Diona made an application to the Supreme Court, seeking a declaration that the Determination was void and an injunction preventing Downer from requesting an adjudication certificate or filing the adjudication certificate as a judgment debt. Diona contended that the Adjudicator had incorrectly awarded a set off claim by Downer, in response to Diona’s liquidated damages claim, in the amount of $30,000 on account of two extension of time claims (EOT Claims).

Diona argued that the Adjudicator had not fulfilled the requirements of s 22(2)(b) of the SOP Act because the Adjudicator had failed to give any reference to, or consideration of, Diona’s contention in its adjudication response submissions that Downer was not entitled to these extensions of time, due to the operation of a time bar in the contract.

 

Did the Adjudicator consider the time bars?

The central question was whether the Adjudicator considered the provisions of the contract. Under section 22(2)(b) SOP Act, an adjudicator must consider the provisions of the construction contract.

To determine if the Adjudicator did consider the contractual provisions, especially those containing the time bar, the Court looked at the submissions made by both parties and the Adjudicator’s determination.

The Court noted that Downer had ‘devoted a number of pages to its contentions concerning extension of time and, in particular, its asserted entitlement to EOT 18 and EOT 21’. This was contrasted with Diona’s submissions, the Court found did not properly engage with Downer’s EOT Claims. Diona’s submissions stated:

‘Determinations of claims for…extension of time…by Diona are final and cannot be disturbed except by raising a Claim under the Contract, see relevant clauses of the Subcontract.’

The Court highlighted a part of the Adjudicator’s reasons which stated:

‘The Act at section 22(2)(b) requires the adjudicator to consider the provisions of the construction contract when making the determination’

Having regard to the Adjudicator’s express reference to s 22(2)(b) of the SOP Act, the Court stated that there were several reasons why the Adjudicator did not refer to the dispute clause in the Determination. Firstly, the Adjudicator may have felt that Diona did not properly articulate and develop the time bar argument. Alternatively, the Adjudicator may have misunderstood the submissions. The Court concluded that:

‘The Adjudicator may have come to the wrong decision about Dower’s entitlement to EOT 18 and EOT 21. But that, without more, is not a basis to set aside the set aside the determination.’

The argument that Diona sought to raise, while potentially valid, was not properly articulated. Therefore, it could not be inferred that the Adjudicator had failed to consider the provisions of the subcontract as required by s 22(2)(b) of the SOP Act.

 

So what?

The significance of this case is that it shows that what appear to be errors or failures to consider an argument by an adjudicator will not always result in a basis to set aside the adjudicator’s determination. The adjudicator’s decision can be rough and ready, provided the adjudicator makes their decision in accordance with the SOP Act. Payments made under SOP Act are on account only and may be determined on a final basis at a later stage.

 

Case article – Brolton Group Pty Ltd v Hanson Construction Materials Pty Ltd

/in

In Brolton Group Pty Ltd v Hanson Construction Materials Pty Ltd [2020] NSWCA 63 (Brolton), the NSW Court of Appeal considered the jurisdictional and procedural fairness grounds of an adjudicator’s determination.

Background

Brolton was contracted by Hanson to build a quarry processing plant at Bass Point. The parties agreed on a guaranteed maximum price of $85 million (excluding GST) in which Brolton was entitled to claim monthly progress payments on the last Tuesday of each month. Hanson claimed liquidated damages and the contract was eventually terminated on 3 October 2018. In August 2019, Brolton served a payment claim on Hanson. The payment claim claimed work up to September 2018 as well as interest on unpaid amounts to August 2019. The adjudicator determined in favour of Brolton, issuing an adjudication amount of $2,877,052.75. Hanson challenged the decision in the Supreme Court, with the Supreme Court finding in favour of Hanson. This resulted in the appeal by Brolton to the NSW Court of Appeal.

The Court’s decision

Brolton raised two main grounds of appeal. The first and most pertinent issue, concerning jurisdiction, centred predominantly on the availability of a reference date on which Brolton could make its payment claim.
Importance of jurisdiction and the trouble of jurisdictional error
Under the Building and Construction Industry Security of Payment Act 1999 (NSW) (SOP Act) section 22, an adjudicator is given the statutory authority to determine the amount of a progress payment, the date on which such amount became payable and the rate of interest payable on any such amount. The importance of section 22 is that it sets out the jurisdiction of an adjudicator. As the saying goes, with great power comes great responsibility. While the adjudicator is given the power to make these determinations, section 22 sets out the limited factors that the adjudicator can consider. These are the responsibility components of the adjudicator’s determination. Two of the relevant factors to consider in Brolton was the provisions of the SOP Act and the payment claim.
While adjudicators are given the power to make determinations, they can only do so in certain circumstances or if there are specified preconditions. In the legal world, this is called a ‘jurisdictional fact’. As Gleeson JA described in Brolton (at paragraph 28), the term jurisdictional fact is used to describe ‘any precondition which a statute requires to exist in order for the decision-maker to embark on the decision-making process’. Jurisdictional facts fall into two types:

1. The existence of an identified state of affairs; or
2. A state of satisfaction of the decision-maker as to an identified state of affairs.

A jurisdictional fact gives a decision-maker the power to make the decision. If it exists, then an adjudicator can make a determination. In this way, the reference date activates the adjudicators powers to make a determination under the SOP Act.
Under the SOP Act, a claimant is only able to make a payment claim when there is a reference date under the construction contract. Therefore, the existence of a reference date is a jurisdictional fact that falls into the first category. This is because the existence or non-existence of a reference date is objective and does not depend on whether the adjudicator is satisfied that a reference date exists. Where an adjudicator exercises its power, but the jurisdictional fact does not actually exist, the adjudicator has made a jurisdictional error..
Getting back to the case, in submitting its payment claim, Brolton claimed in its adjudication submissions that the reference dates for August 2018 and September 2018 were available for the payment claim. Hanson also contended that the September 2018 reference date was available for the progress payment. However, the adjudicator ‘went rogue’ and determined that the reference date was in fact 23 October 2018. There were a few issues with this. Firstly, the 23 October 2018 was not the last Tuesday of the month (which in fact was 30 October 2018). Secondly, the contract had been terminated on 3 October 2018, meaning no further reference dates arose. As the clause entitling Brolton to a progress payment did not continue beyond the termination of the contract, the adjudicator had made a jurisdictional error. The reference date the adjudicator relied on did not exist, and therefore the determination was void and the $2.8 million decision was overturned (as if it had never been made).

Although Hanson succeeded on the first issue, the Court was still minded to consider the second issue on appeal. The second issue concerned the procedural fairness of the adjudicator’s decision. Like jurisdiction, procedural fairness is a legal term that has important consequences for adjudication determinations. Procedural fairness is an aspect of natural justice, a foundational legal principal that sets the standards of how people are to exercise their authority. The concept of procedural fairness means the process in which a decision is made should be just. Procedural fairness requires that parties have the right or opportunity to have their case heard by the decision-maker. If there is a substantial denial of natural justice, the decision-maker’s determination will be void. In this case, the issue of procedural fairness arose because the adjudicator determined that the relevant reference date was a date not submitted by either party. Brolton argued that while procedural fairness was denied to the parties, it was immaterial and should not void the adjudicator’s decision. The Court found that the findings by the adjudicator were a material breach of procedural fairness and therefore there was a breach of natural justice.

Take-away points

While this article has discussed a few technical legal concepts, the main take away points from Brolton are that:
• A progress payment must be linked to a specific reference date. If an adjudicator incorrectly attributes a payment claim to a reference date which does not exist, the determination will be void.
• It is not enough that another reference date is available for the payment claim to be linked to. If the adjudicator goes rogue and determines a reference date not submitted by the parties, the decision will be void.
• Claimants should identify and make it abundantly clear the relevant reference date to which a payment claim relates and make submissions in the adjudication application as to what the relevant reference date is.
• Reference dates are essential for an adjudicator to make a determination. A failure by the adjudicator to appropriately determine a reference date can have dire consequences to claimants.
• Note: The recent amendments to the NSW SOP Act have eliminated the post-termination payment claim issue. Section 13(1C) now states that for construction contracts that have been terminated, a payment claim may be served on and from the date of termination. This change will only apply to contracts entered into after 21 October 2019.

What’s in a name?: The Supreme Court Reviews ambiguity in SoPA Payment Claims

/in

Those who are familiar with the Building and Construction Industry Security of Payment Act 1999 (‘the Act’) will likely be aware that the provisions it contains are quite strict, and can leave parties out in the cold when they fail to comply with what are seemingly administrative oversights.

However, the overarching purpose of the Act is ultimately to keep money flowing through the construction system, aimed at ensuring those who perform building and construction works, or supply goods and services to construction projects are able to be paid.

The Supreme Court of New South Wales, in the recent decision of decision Modog Pty Ltd v ZS Constructions (Queenscliff) Pty Ltd [2019] NSWSC 1743 reminded parties of this fact when asked to turn its mind to issues of ambiguity in payment claims and whether a party could be allowed to have an adjudication determination quashed on the basis of technicalities.

The Facts

The facts of the case were reasonably clear and did not form a substantial component of the dispute between the parties. In September 2016, Modog Pty Ltd (‘Modog’) entered into a design and construct head contract with Wyndora 36 Pty Ltd (‘Wyndora’) for the development of senior living apartments at a property located along Wyndora Avenue in Freshwater. Modog then entered a sub-contract with ZS Constructions (Queenscliff) Pty Limited (ZS Queenscliff) for the demolition of the existing structure and the construction of the new seniors living complex, including apartments, basement parking and associated site works (‘the Sub-Contract’).

In March 2018, the Sub-contract was varied to engage ZS Queenscliff to provide Construction Management and procurement services, for which ZS Queenscliff would receive a project manager’s allowance, a contract administrator’s allowance and payments for subcontractors and suppliers to be made at the end of each month.

ZS Queenscliff was part of a wider group of entities, which also included ZS Constructions (Australia) Pty Ltd (‘ZS Australia’) and Zaarour Investments Pty Ltd had been engaged as the project manager for the project. Mr Christopher Zaarour was employed by ZS Queenscliff, was the director of ZS Constructions Pty Ltd and was the primary contact with Modog for the duration of the project.

The further sub-contracts on the project were administered by ZS Queenscliff, however invoices from sub-contractors had historically been issued to a mixture of Modog, Wyndora and ZS Australia, as opposed to ZS Queenscliff. During the course of the project, ZS Queenscliff and Modog adopted a progress payments process in which Mr Zaarour would, on behalf of ZS Queenscliff, prepare and email a payment summary sheet listing all amounts due for procurement and management services, as well as materials acquired, and work completed by trade contractors.

On 29 August 2019, Modog issued a Show Cause Notice to ZS Queenscliff and terminated the Sub-contract on 13 September 2019.

The Payment Claim and Adjudication

On 11 September 2019, ZS Queenscliff served a payment claim on Modog which was comprised of seven emails, from Mr Zaarour using an email signature from Zaarour Sleiman and containing a reference to ZS Australia in fine print at the bottom of the email.

The emails attached supporting invoices from suppliers, and followed the process adopted in earlier progress payments, where sub-contractors and suppliers had addressed their invoices to a mixture of the entities involved with the project, and not to ZS Queenscliff, who were issuing the payment claim.

The payment claim served on Modog was, as highlighted by the Court, unclear in the following respects:

  • It did not specifically assert that it was a progress payment claim under the Act;
  • It did not specify the reference date or refer to the clause within the contract upon which the progress payment was based;
  • It failed to ask Modog to pay ZS Queenscliff;
  • It did not include a total for the sum claimed, only determinable by a thorough review of the claims

Modog, in turn responded to the payment claim with payment schedules which certified the amount payable in respect of the Claim was nil.

The matter proceeded to an adjudication, where, on 23 October 2019, the adjudicator found in favour of ZS Queenscliff in the sum of $89,111.89 (GST incl.).

Modog challenged the decision of the adjudicator before the Supreme Court of Sydney, seeking orders that the Adjudication Determination of be deemed void, that the determination be quashed, and ancillary relief.

The Disputed Issues

At the hearing, Modog challenged the decision of the adjudicator on 3 primary grounds:

  • Whether the 11 September 2019 emails constituted a payment claim within the meaning of s13(1) of the Act;
  • If the emails did constitute a payment claim, whether the claim was sent by ZS Queenscliff as a person who was entitled to seek a determination for the purposes of s17 of the Act; and
  • Whether the Adjudicator has committed a jurisdictional error by allowing multiple payment claims in respect of a single reference date?

The Arguments, Decision and Reasoning

Issue 1: Was there a Payment Claim:

The argument advanced by Modog was effectively, ZS Queenscliff had not submitted a valid payment claim as they did not specifically demand payment from Modog (i.e.: did not say, Modog must pay ZS Queenscliff the sum of $X.). Modog relied on the fact that the invoices provided in support of the payment claim, were addressed to various entities, not ZS Queenscliff, and that ZS Queenscliff could not establish they were actually entitled to the money claimed for.

Modog argued that ZS Queenscliff had indicated invoices would be sent at a later time, which Modog was to pay as directed and that, pursuant to the Court’s decision in Quickway Constructions Pty Ltd v Electrical Energy Pty Ltd, ZS Queenscliff had not served a payment claim pursuant to clause 13(1) of the Act.

The counter argument raised by ZS Queenscliff relied upon the case of Icon Co NSW Pty Ltd v Australia Avenue Developments Pty Ltd [2018] to support their position that Modog had simply misunderstood the payment claim, and that this could not be a basis for quashing the adjudicator’s decision. ZS Queenscliff argued the fact that the invoices were addressed to other parties did not invalidate the payment claim as they were simply disbursements to be paid to suppliers.

Ultimately, the Court favoured the position raised by ZS Queenscliff, noting there is nothing within the Act that requires a payment claim to state the total of the sum claimed. The Court stated and that even if the invoices in support of the payment did require Modog to direct payment elsewhere, as long as ZS Queenscliff had an entitlement to the sum under the contract, this did not invalidate the payment claim itself.

Issue 2: Was the Payment Claim Sent by ZS Queenscliff?

Modog then raised the issue that, as the 11 September 2019 email enclosing the payment claim was sent by Mr. Zaarour, using an email signature that did not belong to ZS Queenscliff, and the only legal entity named in the email was ZS Australia, the payment claim had not been served by the appropriate entity for the purposes of s17 of the Act.

The counter argument raised by ZS Queenscliff was that these errors were irrelevant in light of the fact that the previous correspondence between the parties had been exchanged in much the same way, including when detailing the terms of the caries contract agreements, and the point was not taken at the contract negotiation stage.

The Court ultimately agreed again with ZS Queenscliff, making the point that not was not actually disputed that ZS Queenscliff was entitled to make the payment claim and made the determination that the email payment claim had simply been sent by Mr Zaarrour in his capacity as the project manager, on behalf of ZS Queenscliff.

Issue 3: Was there an issue with multiple emails being used to comprise the payment claim?

Finally, Modog sought to raise the point that multiple invoices had been served on them in the emails from ZS Queenscliff and that it was not open for ZS Queenscliff to seek to have all invoices adjudicated.

Relying on the decision of the court in Rail Corporations of NSW v Nebax Constructions [2012] NSWSC6, this point ultimately failed as well, on the basis that, when viewed in the context of the previous conduct between the parties, and the nature of the invoices supplied, Modog had been more accurately provided with one payment claim, and a number of invoices in support of the claim.

What does this decision mean?

This decision serves as a timely reminder to parties that the Building and Construction Industry Security of Payment Act 1999 (‘the Act’) is intended to allow money to flow through to sub-contractors. Parties should be mindful of this purpose when considering whether to attempt to argue a payment claim on the basis of a minor technicality or ambiguity.

If you or someone you know wants more information or needs help or advice in relation to NSW’s security of payment legislation (or any other state’s or territory’s equivalent), please contact us on (02) 9248 3450 or email info@bradburylegal.com.au.

Expertly building evidence: Lessons learned from White Constructions

/in ,

Case note: White Constructions Pty Ltd v PBS Holdings Pty Ltd [2019] NSWSC 1166

In White Constructions, Hammerschlag J considered the issue of delay damages. White Constructions was the property developer of a site in Kiama NSW. The development involved the development and subdivision of 100 lots and required design and installation of sewer infrastructure. These works required a s 73 Certificate issued by Sydney Water before subdivision could occur. White Constructions appointed the Defendants to assist with the design and approval works needed as part of the development and resulting subdivision. A substantial part of the judgment was devoted to the preparing and designing of the sewer designs and the approval of Sydney Water, including the different types of sewage systems, Sydney Water’s preference in relation to these systems, preparation of option reports and correspondence between the Superintendent, the Defendants and Sydney Water.

The discussions between Sydney Water, the Superintendent and the Defendants took considerable time. As a result, White Constructions alleged that the delay in coming to the approved sewage design caused White Constructions to be liable to their building contractor for delay damages. In arguing the substance of the dispute, the parties tendered complex expert evidence. As a result, the Court appointed an expert to assist in interpreting and assessing the expert evidence presented.

With the expert’s assistance, Hammerschlag J criticised the experts’ approach to determining the delays attributable to the sewage works. Both experts used methods derived from the United Kingdom Society of Construction Law, the Delay and Disruption Protocol (the Protocol) in analysing the delay. The Protocol identifies six different methods of delay analysis, but Hammerschlag J held that the inclusion of a delay analysis method in the Protocol does not necessarily mean it should be used. While the Protocol methods have been endorsed in other cases, the analysis of delay must pay close attention to the actual evidence of what was happening on the ground of the project. The delay analysis must show and prove that, on the balance of probabilities, the delay:
• played a role in delaying the project;
• how it delayed the project; and
• how much it delayed the project.

This approach is in line with the common law common-sense approach to causation which the High Court referred to in March v E&MH Stramare Pty Ltd (1991) 171 CLR 506.

A lot of value in White Constructions comes from Hammerschlag J’s analysis of what evidence is needed in cases where delay is alleged in construction matters. Firstly, the Court stated that close attention must be paid to the facts of the matter, rather than the opinion of experts. This evidence should not be general in nature, but specific in that it is able to precisely identify delays in the project. This evidence should be a contemporaneous record of the project. A classic example of this kind of evidence is a site diary which records the day to day of the project, as well as specific cause and effect of each delay.
• what works were undertaken/completed;
• the instructions received from the client;
• the delays/any complaints of delays and how they have affected other activities;
• which personnel were onsite; and
• any other relevant details

The Court found that it was important that the contemporaneous record identified which activities were adversely affected by the delays. For example, if the works of one contractor were delayed and, as a result, caused delay for another contractor, the site diary should record these details. Failing to record these details means that it is harder, if not near impossible, for parties to establish that there was in fact a causal link and adverse effect.

How does White Constructions impact a project?

White Constructions shows the importance of proper project documentation. Most importantly, the site diary, or similar contemporaneous document, should be the primary record of the specific of what is happening on site and how specific events affect different contractors. Proper record keeping, while it may be administratively burdensome, allows the Court to analyse and determine the proper entitlements of the parties if the project ever comes into dispute. While other evidence can be adduced in pursuit of proving delay, it runs the risk of being generalist in nature and not enough to prove the causal link of the delays.

The lessons learned in White Constructions may also have some application in respect of other delay related mechanisms under construction contracts. For example, a comprehensive site diary would also be useful in determining any claim for an EOT claim. However, it is important to note that these types of claims are largely determined by the contract and its processes for determining what is in fact an EOT. Nevertheless, contemporaneous records of what has happened and how this has affected the project is useful in establishing a claim by a party as to their entitlements.
Another important point that comes from White Constructions is ensuring experts are given the proper lay evidence to ensure that they can properly opine on the project. While it does not displace the role of lay evidence such as site diaries, it can assist in assisting the Court in considering and making appropriate decisions on what the parties are entitled to.

If you or someone you know wants more information or needs help or advice, please contact us on +61 2 9248 3450 or email info@bradburylegal.com.au.

New laws in relation to multi-storey residential strata schemes

/in

On 27 September 2018, the NSW government enacted amendments in relation to residential strata schemes. In introducing the bill, Minister for Innovation and Better Regulation Matt Kean MP said: “Currently more than two million New South Wales residents are working as strata industry professionals or strata owners, or are living in strata-titled townhouses or units.”

The amendments are aimed at reducing defects arising from defective construction of residential strata schemes. The Amending Act is called the Strata Schemes Management Amendment (Building Defects Scheme) Act 2018. It makes changes to Part 11 of the Strata Schemes Management Act 2015 (the Act) and will take effect when the government announces so in the NSW Government Gazette. The Legislation Review Committee indicates this will happen ‘once the regulations are operational’.

Who is affected by this amendment?

Firstly, Part 11 only applies to contracts entered into on or after 1 January 2018.

Secondly, Part 11 only applies to ‘residential building work’ carried out on any part of a multi-unit dwelling strata scheme of at least four storeys.

Thirdly, Developers cannot contract out of these provisions.

The Act

At its core, Part 11 was intended to ‘streamline the identification and rectification of defects for the benefit of strata residents, builders and developers’. The Act contains the following provisions:

  • A developer must arrange for an inspection report. This means they must appoint a qualified, impartial and independent person as a building inspector, generally within 12 months of completion of the building works;
  • This building inspector must carry out an inspection of the building work and provide an interim report between 15 months and 18 months after the completion of the building work. This interim report must identify any defective building work and attempt to identify the causes of the defective work;
  • Within 18 months of the completion of the building, the developer must then arrange for the same building inspector to provide a final report on the building work;
  • The building inspector must carry out a final inspection and provide the final report to all parties between 21 months and 2 years after the completion of the building work. This report is to identify both defects not rectified, and defects arising from attempts to rectify defects. The report also must specify how defects should be rectified;
  • All costs of inspection and reporting are borne by the developer;
  • Before commencing a development, a developer must also lodge a building bond which is worth 2 percent of the total development contract price, it is to be given to the Secretary of the Department of Finance, Services and Innovation (the Secretary);
  • The 2 percent bond will be used by the owners corporation of a building as security for funding to rectify any defects in the building that arise. It can be claimed up to 2 years after the date of completion of the building work, or within 60 days after the building inspector’s final report – whichever is later; and
  • The Secretary,  owners corporation or the developer can apply to the NSW Civil and Administrative Tribunal to have the contract price determined by the Tribunal..

Some of the decisions made by the Secretary are reviewable, but such an application for review must be made within 14 days after notice of the decision is given.

The amendments

Developers of strata schemes need to be aware that there are now new requirements in relation to lodging a bond and providing information to authorities in relation to the contract price. Additionally, the Secretary has been given increased investigative powers in relation to the contract price, building bonds and building defects.

The amendments are as follows:

  • The Amending Act now makes it mandatory, before an application can even be made for an occupation certificate, for the developer to give the 2 percent building bond to the Secretary. Failing to do this will attract a significantly increased penalty: originally $22,000, the maximum penalty is now $1.1 million and an additional $22,000 for each day the offence continues;
  • There is also a new penalty where a developer provides the Secretary with false or misleading information about the contract price or amount required to be secured by the bond (maximum penalty: $1.1 million for corporations, $22,000 for any other case);
  • A requirement that the developer and owners corporation agree on the amount required to rectify any building defects identified by the inspector. They may use a wide range of methods to determine the cost. If they cannot agree, the Secretary may appoint a quantity surveyor to determine this amount;
  • The deadline for an owners corporation to claim the secured amount to rectify defects has been extended, from 60 days after the building inspector’s final report is issued to 90 days;
  • The Secretary may consider it appropriate to release the developer from the bond, if the interim report does not identify any defects, or if some of the amount has been claimed and both the owners corporation and developers agree to cancel the remaining amount;
  • Where the building bond given by a developer is insufficient to cover the amount required to be secured, the Secretary may recover the required amount in court as a debt from a developer. The owners corporation may then claim from the Secretary;
  • The Amending Act grants new powers of investigation and enforcement of Part 11 to any officer authorised by the Secretary. These powers are for the purposes of investigation, monitoring and enforcing compliance with Part 11, and/or for obtaining information and records to be used in administering Part 11. For these purposes:
    1. An authorised officer may by notice in writing to a person require them to provide information or records;
    2. An authorised officer may require a person or the director of a corporation to answer their questions, if they suspect this person has knowledge about Part 11 matters;
    3. An authorised officer may enter premises at any reasonable time, with or without a search warrant, and do certain activities: make examinations and inquiries, direct a person to produce records, examine and inspect records, copy records, and seize anything suspected of being connected with an offence. Where the premises are predominantly residential, a warrant or the consent of the occupier is required for entry;
    4. An authorised officer may obtain a warrant to enter and search premises for evidence of contravention of Part 11;
    5. Penalties for refusing to comply with these requirements, or obstructing an authorised officer, gives rise to penalties up to $4400 for a corporation, or $2200 for any other case. This is unless reasonable excuse can be shown, such as client legal privilege or a privilege against self-incrimination; and
  • A building inspector is protected from action, liability or claim where they act in good faith and for the purposes of their Part 11 functions. Professional associations will however have powers to impose conditions on the functions of building inspectors. A person authorised by the Secretary is also protected from liability, however the Crown may be sued.

Conclusion

The NSW government is taking a keen interest in the processes of identification and rectification of defective building works in strata schemes. It is also clamping down on attempts to circumvent the Act.

In this changing legal environment, it is essential that parties involved in constructing residential strata developments, including developers and owners corporations, understand these changes to their rights and obligations. For developers affected by these provisions, the first deadline to be met could be as soon as 1 January 2019 for the appointment of a building inspector.

Please contact us, should you require any further information, on +612 9248 3450 or email info@bradburylegal.com.au.