Tag Archive for: Construction

Contractual interpretation: What did we even agree upon?

/in ,

It is the question as old as human trade and commerce: when we made that agreement, what did we mean?

This is a deceptively simple question. It may appear to parties with amicable relations that the meaning of a document is clear, but when a dispute opens up, what tends to happen is that each party will stretch every definition to suit its purposes.
As will become clear, courts are still grappling with difficult questions about how an agreement should be interpreted, and what evidence put forward by the parties can be considered to discern its meaning.
We consider some basic principles to do with contractual interpretation, and look at a recent example of the circumstances in which courts will look at negotiations between the parties and the effect this has on the meaning of the agreement.

Basic principles

Where there is a written contract between two parties that are legally represented and commercially experienced, the law will likely consider this contract to be the complete statement of their legal rights and obligations. In some cases, a contract may be both oral and in writing, but proving this is onerous.
As a result, where there is a dispute, the contract is the first thing that the lawyers and judges will consider. The contract is considered to reflect how the parties intended to allocate risk.
When looking at a contract, the court will assess and interpret the contract to give effect to what is called the objective intention of the parties. This is not what was actually in the minds of the parties. Rather, it is what a reasonable person, a third-party bystander, would understand the words or actions of the parties to show about the parties’ intention.
In the commercial context, this means the court will look at the words used in drafting the contract and determine what they mean to a reasonable businessperson informed about the circumstances of the case.

But wait there’s more

What is said above does not mean that the actions of the parties are irrelevant. Far from it.
In fact, it is sometimes necessary for courts to consider the surrounding circumstances of an agreement, so that they can determine what the intentions of the parties are with respect to what exactly constitutes the agreement and what its terms mean.
This might seem contrary to the court’s tradition of only looking at the contract. However, it will generally only be done when there is ambiguity in the words of the contract.
For example, in Toll (FGCT) Pty Ltd v Alphapharm Pty Ltd (2004) 219 CLR 165, the High Court stated that it is not what the parties think about their rights and obligations that govern contractual relations. Rather, it is the words and conduct of each party that would lead a reasonable person in the position of the other party to believe.
Ten years later, the High Court again commented on the use of evidence outside the contract in Electricity Generation Corporation v Woodside Energy Ltd (2014) 251 CLR 640. In this case, the High Court said that evidence of the parties’ actual (subjective) intentions is not relevant to construction. What is relevant is the evidence of surrounding circumstances known the parties.
External circumstances can be considered by the courts when interpreting contracts between disputing parties.

So how does this all work?

If courts are supposed to consider the contract as the full statement of the parties’ rights and obligations, but they are able to look at circumstances beyond the contract, how does a judge determine what is the agreement?
Firstly, the contract is still the primary document that is interpreted. The evidence considered by a court of what has been said or what has happened outside of the contract cannot be used to give the contract a meaning that is contrary to what the contract clearly states.
Put another way, evidence outside of the contract cannot be used to add to, vary or contradict the language of the written contract. This is the case no matter how unjust or inconvenient the written terms are. This makes sense, as effective relations depend on the meaning of an agreement being fixed and clear.
Permitting outside factors to change the meaning of a contract introduces significant uncertainty. As any businessperson will know, where there is uncertainty there is conflict. A party could for example attempt to impose its own view on the meaning of the document. External conduct is used to make the meaning of the contract clearer, not to change it. In practice, however, the line between these two can be very difficult to draw.
Secondly, matters outside of the contract become relevant only where there is ambiguity or more than one meaning in what is inside the contract. Words may have different meanings in different contexts, so the context is important in choosing the right interpretation.
To this end, courts may consider the commercial purpose of the contract, the market and industry in which it arose, and the factual background of the agreement. All of this can shed light onto what the parties “must have” intended when they drafted the contract.
It is important to note that courts will only consider outside circumstances that are known to both parties.
However, courts will only consider these factors if the meaning of the written document is not clear. Negotiations that occurred prior to the signing of the agreement are also rarely considered, for the simple reason that they do not often show what was agreed.

For example …

Cherry v Steele-Park [2017] NSWCA 295 was a case that turned on the meaning of a deed of guarantee. Specifically, whether this deed of guarantee required the guarantor to pay the damages that resulted from the failure of their company to complete a contract for sale of land. The guarantor argued that the deed only covered the amounts promised for extending the contract’s completion date. The difference was around $145,750.
The case appeared to challenge the principles talked about above.
The argument was around whether the meaning of term had to be ambiguous before a court would admit evidence outside of the contract to explain its meaning. What happens when a term that appears to have a plain meaning “becomes” ambiguous only when outside material is introduced?
The answer is that as long as the evidence is relevant as information about the genesis or purpose of the transaction, it can bear on the contractual language and can be considered. Then the court will make a conclusion about whether the written terms are clear or ambiguous.
In Cherry v Steele-Park, Cherry wanted to include in evidence emails exchanged between the parties, that represented negotiating positions that were communicated between the parties. (As a side note, it was important that both parties knew about these emails when entering the contract.)
The Court considered the emails. However, the case ultimately reinforces not challenges the conclusions talked about above. The interpretation of the clause given by the court ultimately did not bend to what was said in these emails.
Rather, the Court considered as primary the terms and the structure of the contract, including the definitions and the generality of their language. The interpretation put forward by Cherry was some but clearly not all of the guarantee.
The Court concluded that the emails did not defeat “the wide words in the Guarantee”. The emails showed that there may have been a commercial purpose to make a limited guarantee. However, this context could not overcome the content of the Guarantee. Or, as Leeming JA stated, “such context – even relatively powerful evidence of context such as the present – does not warrant doing the violence to the general language of the document executed by them that they require.”
It was in effect a warning, that regardless of how persuasive evidence of negotiations is, it will not limit or take away from what is stated in a contractual document.

Conclusion

Prevention is always better than the cure. In the early stages of a commercial agreement, a little expense given to ensuring a contract tabled between the parties truly expresses your intentions goes a long way to preventing protracted disputes.
Problems can arise even between parties with a great relationship, and as discussed, once a problem does arise courts will be very reluctant to look beyond the written document that was exchanged. What this written document says will be of paramount importance, so it is worth the extra attention.
If you or someone you know wants more information or needs help or advice, please contact us on +61 2 9248 3450 or email info@bradburylegal.com.au

Expertly building evidence: Lessons learned from White Constructions

/in ,

Case note: White Constructions Pty Ltd v PBS Holdings Pty Ltd [2019] NSWSC 1166

In White Constructions, Hammerschlag J considered the issue of delay damages. White Constructions was the property developer of a site in Kiama NSW. The development involved the development and subdivision of 100 lots and required design and installation of sewer infrastructure. These works required a s 73 Certificate issued by Sydney Water before subdivision could occur. White Constructions appointed the Defendants to assist with the design and approval works needed as part of the development and resulting subdivision. A substantial part of the judgment was devoted to the preparing and designing of the sewer designs and the approval of Sydney Water, including the different types of sewage systems, Sydney Water’s preference in relation to these systems, preparation of option reports and correspondence between the Superintendent, the Defendants and Sydney Water.

The discussions between Sydney Water, the Superintendent and the Defendants took considerable time. As a result, White Constructions alleged that the delay in coming to the approved sewage design caused White Constructions to be liable to their building contractor for delay damages. In arguing the substance of the dispute, the parties tendered complex expert evidence. As a result, the Court appointed an expert to assist in interpreting and assessing the expert evidence presented.

With the expert’s assistance, Hammerschlag J criticised the experts’ approach to determining the delays attributable to the sewage works. Both experts used methods derived from the United Kingdom Society of Construction Law, the Delay and Disruption Protocol (the Protocol) in analysing the delay. The Protocol identifies six different methods of delay analysis, but Hammerschlag J held that the inclusion of a delay analysis method in the Protocol does not necessarily mean it should be used. While the Protocol methods have been endorsed in other cases, the analysis of delay must pay close attention to the actual evidence of what was happening on the ground of the project. The delay analysis must show and prove that, on the balance of probabilities, the delay:
• played a role in delaying the project;
• how it delayed the project; and
• how much it delayed the project.

This approach is in line with the common law common-sense approach to causation which the High Court referred to in March v E&MH Stramare Pty Ltd (1991) 171 CLR 506.

A lot of value in White Constructions comes from Hammerschlag J’s analysis of what evidence is needed in cases where delay is alleged in construction matters. Firstly, the Court stated that close attention must be paid to the facts of the matter, rather than the opinion of experts. This evidence should not be general in nature, but specific in that it is able to precisely identify delays in the project. This evidence should be a contemporaneous record of the project. A classic example of this kind of evidence is a site diary which records the day to day of the project, as well as specific cause and effect of each delay.
• what works were undertaken/completed;
• the instructions received from the client;
• the delays/any complaints of delays and how they have affected other activities;
• which personnel were onsite; and
• any other relevant details

The Court found that it was important that the contemporaneous record identified which activities were adversely affected by the delays. For example, if the works of one contractor were delayed and, as a result, caused delay for another contractor, the site diary should record these details. Failing to record these details means that it is harder, if not near impossible, for parties to establish that there was in fact a causal link and adverse effect.

How does White Constructions impact a project?

White Constructions shows the importance of proper project documentation. Most importantly, the site diary, or similar contemporaneous document, should be the primary record of the specific of what is happening on site and how specific events affect different contractors. Proper record keeping, while it may be administratively burdensome, allows the Court to analyse and determine the proper entitlements of the parties if the project ever comes into dispute. While other evidence can be adduced in pursuit of proving delay, it runs the risk of being generalist in nature and not enough to prove the causal link of the delays.

The lessons learned in White Constructions may also have some application in respect of other delay related mechanisms under construction contracts. For example, a comprehensive site diary would also be useful in determining any claim for an EOT claim. However, it is important to note that these types of claims are largely determined by the contract and its processes for determining what is in fact an EOT. Nevertheless, contemporaneous records of what has happened and how this has affected the project is useful in establishing a claim by a party as to their entitlements.
Another important point that comes from White Constructions is ensuring experts are given the proper lay evidence to ensure that they can properly opine on the project. While it does not displace the role of lay evidence such as site diaries, it can assist in assisting the Court in considering and making appropriate decisions on what the parties are entitled to.

If you or someone you know wants more information or needs help or advice, please contact us on +61 2 9248 3450 or email info@bradburylegal.com.au.

CHANGE HAS ARRIVED

/in

Amendments to the Building and Construction Industry Security of Payment Act are finally in force

Late last month changes to the Building and Construction Industry Security of Payment Act 1999 (Act)’ (‘the Act’) came into effect under the Building and Construction Industry Security of Payment Amendment Act 2018 (‘the amendments’), passed in November 2018.
The overarching purpose of the amendments is to address issues of insolvency and late-payments within the industry. They aim to alleviate the impact of these issues on small businesses and subcontractors by promoting cash flow and greater transparency in the contracting chain.
Our regular readers may recall, we have been discussing these changes and their potential consequences over the course of the year, but here is a refresher now that the amendments are in force.

What do the changes mean again?
As of 21 October 2019 the amendments are effective and apply prospectively to all building and construction as contracts covered by the Act, entered into on or after this date.
The changes are extensive and place significant new responsibilities on parties within the NSW building and construction industry. In broad terms, the legislative changes cover the following points:

Investigation, Enforcement and Penalties

Officers of the Department of Finance Services and Innovation have been given a suite of new powers to investigate monitor and enforce compliance with the Act, including but not limited to powers of entry to premises to gather information.
Directors and managers may now be personally prosecuted in circumstances where a corporation has committed an offence, under new provisions introducing the concept of executive liability.
Tougher maximum penalties have been applied, particularly when supporting statements are not supplied.

Adjudication

Confirming previous decisions of the Court, the amendments confirm jurisdictional errors made by adjudicators are now reviewable by the Supreme Court, with the power to effectively ‘carve’ out the invalid sections of adjudicator’s decisions.
The amendments also provide parties with an option to withdraw their application for adjudication in circumstances where the adjudicator is not yet appointed. In circumstances where the adjudicator has been appointed, parties are still able to object to the adjudication application being determined.

Progress Claims and Progress Payments

The amendments have removed the concept of the reference date in making a progress claim, and the due date for payments to subcontractors has been reduced from 30 business days to 20 business days.
The amendments again require payment claims to state that they are in fact payment claims made under the Act.

Conclusion

The changes have far reaching consequences for parties operating within the building and construction industry. It is important for all parties operating within the industry to be aware of the changes and the way in which the amendments may affect their rights and obligations under building and construction contracts.
For an in-depth review of each amendment please see our detailed review on the changes here.
If you or someone you know wants more information or needs help or advice in relation to NSW’s security of payments legislation, please contact us( 02) 9248 3450 or email info@bradburylegal.com.au.

See more! The superintendent and the principal

/in

To those working at building sites, the term “superintendent” may seem as familiar and self-explanatory as “extension of time” or “practical completion”.

However, when disputes arise fine distinctions become important. Even experienced builders, just like experienced judges, have trouble working out what the superintendent is required to do in contentious times.

This is because the superintendent has multiple duties to different parties. They have the difficult job of navigating conflicting interests, and this becomes much harder when the relationship between the principal and contractor has deteriorated.

Although the precise duties of a superintendent will always depend on the terms of the contract, we will describe in general terms some obligations that participants in a building project must be aware of. We will also take a real-life case study to illustrate some of these points.

The role

Sometimes called “contract administrator” or “architect”, the superintendent’s precise role will vary as it is largely determined by the terms of the contract between the principal and the contractor. The parties may agree by contract to restrict or widen the superintendent’s functions, and courts will generally allow this.

However, there are a number of general commonalities to this role across different projects. In most cases, the superintendent has a dual role or function:

  1. On the one hand, the superintendent will often be the agent of the principal, and will perform functions on behalf of the principal such as issuing directions to the contractor, varying the scope, of works, making approvals, or receiving notices;
  2. On the other hand, the superintendent will often be responsible for certifying, assessing and valuing items under the contract, including progress claims, extension of time claims, liquidated damages, and practical completion.

The principal is required to ensure that for the second set of functions above, the superintendent act “honestly and fairly” (or otherwise, “reasonably and in good faith”).

Often this is an obligation to exercise impartial and independent judgment, and to reach a decision without taking improper considerations into account. They should afford procedural fairness to both parties, giving notice of the issues it is considering and allowing both parties to communicate to them their submissions.

In general, for these second set of functions, the interests of not only the Principal, but also those of the Contractor, must be considered. All too often, superintendents fail to understand their obligations of independence and this triggers court proceedings.

In practice, this dual role can be complicated. Superintendents are generally appointed by the principal. They are very often either a part of a firm consulting to the principal, or they are an employee of the principal. Even if there is no pressure exerted by the principal, they are paid by the principal. Exercising their judgment impartially in this context can be very challenging.

A superintendent is not a party to the contract. It is unlikely that they will themselves be the subject of court proceedings. However, their decisions may give rise to disputes as between the principal and contractor.

Case Study

The New South Wales Court of Appeal has given some guidance for what is considered appropriate action by a superintendent under a construction contract, in the case Peninsula Balmain Pty Ltd v Abigroup Contractors Pty Ltd [2002] NSWCA 211.

Peninsula and Abigroup entered into an AS2124 building contract. Abigroup sought payment of a progress claim. The following month, Peninsula issued a notice to Abigroup requiring Abigroup to show cause that a contractual right to terminate should not be exercised, and cross-claimed for liquidated damages under the contract.

In response, Abigroup moved to terminate the contract, claiming that Peninsula had breached the then Trade Practices Act (which has since integrated into the broader Australian Consumer Law), for failing to disclose an agency agreement for design and construction projects between Peninsula and the superintendent.

The Court considered the whether Peninsula contravened the Trade Practices Act for failing to disclose to Abigroup the agency agreement with the superintendent?

On appeal, Hodgson JA held:

“the superintendent is the owner’s agent in all matters only in a very loose sense, and that, when exercising certifying functions in respect of which the superintendent must act honestly and impartially, the superintendent is not acting as the owner’s agent, in the strict legal sense.”

The Court concluded that the superintendent is to exercise their power in the interests of both parties and, is to act honestly and impartially and not as an agent of the owner in undertaking certifying functions such as assessments of variations, delays and progress claims.

There was also an argument that the superintendent should have but failed to exercise its power to award an extension of time. It was common ground that Peninsula Balmain had caused delay, but that Abigroup had not applied for the extension of time or followed the proper procedure. However, the extension of time clause included a paragraph that read: “Notwithstanding that the Contractor is not entitled to an extension of time the Superintendent may at any time and from time to time before the issue of the Final Certificate by notice in writing to the Contractor extend the time for Practical Completion for any reason.”

Hodgson JA found that, even though Abigroup had not applied for the extension of time, “this power is one capable of being exercised in the interests both of the owner and the builder, and in my opinion the Superintendent is obliged to act honestly and impartially in deciding whether to exercise this power”. In the facts of the case, the finding was that if the superintendent had acted fairly and impartially, they would have awarded the extension of time. The date for practical completion was extended, and liquidated damages were reduced.

This ruling was dependent on the particular extension of time clause of the case, and the facts of the dispute. However, it powerfully reinforces the point that even though the superintendent is the agent of the principal, they are obliged to act honestly and fairly in discharging certain functions, unless the contract says otherwise.

Conclusion:

In conclusion, the role of a superintendent is very demanding and requires a high level of understanding of contract law, the responsibilities, the specifics of the project, and a high skill of identifying and managing conflicts. If you have any queries about your obligations under a construction contract, please contact us on +61 2 9248 3450 or email info@bradburylegal.com.au