Tag Archive for: contracts

$1 per day LD’s in residential building contracts no longer rules out claims by owners for general damages for delay

/in

Facts

In Cappello v Hammond & Simonds NSW Pty Ltd [2020] NSWSC 1021, Hammond & Simonds NSW Pty Ltd (Builder) entered into a standard form Housing Industry Association NSW Residential Building Contract for Works on a Cost Plus Basis (Contract) with Mr and Mrs Cappello (Owners) to renovate the ground floor of their house in Haberfield.

The LD’s for late completion was $1 per working day which was consistent with the default position under the Contract.

The works under the Contract were completed approximately 7 months late and the Builder made no requests for any extensions of time.  The Owners made various claims against the Builder, among them, was a claim for general damages for delay in the sum of $30,000.

Builder’s case

The Builder claimed that the Owners were only entitled to recover $1 per working day for delay in accordance with the LD clause in the Contract and that by making provision for LD’s in the Contract, the parties were taken to have intended to exclude a right for the Owners to also claim general damages for delay against the Builder.

Owners’ case

The Owners’ claimed that the LD clause did not provide the only remedy for the Builder’s delay because if it did, it would be void due to section 18G of the Home Building Act 1989 (NSW) (HBA) as it would have the effect of restricting the Owners’ rights in relation to the benefit of the warranty under section 18B(1)(d) of the HBA (that the work will be done with due diligence and within the time stipulated in the Contract).

What did the Supreme Court decide?

The Court found that:

  • the LD clause should not be interpreted as providing the only remedy for delay. Rather, by specifying the amount of LD’s so low at $1 per working day, instead the parties intended for the Owners to also have a right to claim general damages for delay (although in this case general damages were ultimately not awarded as the Owners did not meet the test for general damages that applies to breach of contract);
  • that an LD clause which limits a party to claiming nominal damages for a breach of a warranty restricts the rights of that person in respect of the warranty and is therefore void under section 18G of the HBA (which says that any agreement that restricts or removes the right of a person in respect of any of the statutory warranties is void); and
  • the outcome may have been different if the LD clause provided for the payment of a substantial amount in LD’s.

What does this mean for residential builders?

  • builders will be exposed in relation to existing contracts that stipulate $1 per working day (or a nominal amount for LD’s) as owners would be entitled to LD’s of $1 per working day plus general damages for delay by the builder;
  • any attempt to limit the builder’s liability for delay (including inserting a nominal amount for LD’s) will be void under section 18G of the HBA;
  • if builders wish to exclude general damages for delay in new contracts, they should insert a rate for LD’s that offers the owner a “substantial right” to compensation not just a nominal amount for breach of the statutory warranty (that the work will be done with due diligence and within the time stipulated in the contract); and
  • in order to limit the builder’s exposure for not only LD’s but also general damages for delay, builders should ensure that they claim all available EOT’s in relation to extending the contract period

CONTRACTOR STRIKES SECURITY OF PAYMENT GOLD BY SKIRTING THE MINING EXCEPTION

/in

Mining owners and operators in most Australian States[1] will be aware of the “mining exception” in security of payment legislation.  The mining exception excludes ‘the extraction (whether by underground or surface working) of minerals, including tunnelling or boring, or constructing underground works for that purpose’[2] (Mining Exception) from the definition of the term “construction work” and, consequently, the ambit of statutory interim progress payment mechanisms.

However, in a decision handed down on 11 November 2020, the NSW Supreme Court[3] followed the approach of the Queensland courts[4] by construing the Mining Exception narrowly in favour of contractors and subcontractors.  In short, the Mining Exception does not  extend generally to some broad category of mining industry operations.[5]

Facts

Downer EDI Mining Pty Ltd (Downer) was engaged by Cadia Holdings Pty Ltd (Cadia) the operator of the Cadia East underground panel cave mine south-west of Orange, under a “Works Contract” dated 16 November 2018 (Contract), to perform “development phase” works, being (for the most part) underground works to provide access to the proposed undercut and extraction levels for future extraction of minerals in the “production phase”[6]

Downer proceeded to adjudication on a payment claim served on Cadia.  An adjudicator appointed under the Building and Construction Industry Security of Payment Act 1999 (NSW) (SOPA) determined that Cadia pay Downer $1,017,741.72.[7]

Cadia challenged the determination on two grounds:

  1. the Mining Exception applied so the Contract was not a “construction contract” within the meaning of the SOPA; and
  2. there was no available reference date to support Downer’s payment claim.

Decision

Cadia’s challenge to the adjudication determination was unsuccessful on both grounds.

Stevenson J framed the effect of the Mining Exception as excluding ‘from the definition of “construction work”, the following works:

  • extraction (whether by underground or surface working) of minerals;
  • tunnelling or boring for the purpose of extraction (whether by underground or surface working of minerals; and
  • constructing underground works for the purpose of extraction (whether by underground or surface working) of minerals.’[8]

His Honour held that the heart of the question of the application of the Mining Exception to a contract is what a contractor undertakes to do under the contract in question, not what work that contractor actually does[9] (which comes to be answered later).

The works under the Contract did include “tunnelling or boring” as well as “constructing underground works”.  However:

  1. these activities were not for the “purpose of” extraction of minerals; and
  2. the Contract required Downer to undertake work beyond these activities which fell within the meaning of “construction work” or the supply of “related goods and services”.

On considering generally whether activities performed by a contractor are for the “purpose of” extraction of minerals, His Honour:

  1. agreed with Fryberg J in Thiess that the relevant purpose should be decided ‘by reference to what a reasonable person in the position of the parties would conclude as to the object of what purpose of the contract’[10];
  2. held that the Mining Exception is to be construed narrowly to benefit the subcontractor[11];
  3. held that a close “proximity” between the act of extraction and the tunnelling and boring or construction of underground works was required (and this was not so in this case, where the extraction phase would not begin until 2022 after subsequent works)[12];
  4. considered that “extraction” does not include work “associated with” or “preparatory to” extraction[13]; and
  5. noted that the SOPA expresses where there is an intention to bring in ancillary activities, which is not the case with the Mining Exception[14].

Further, in this case, His Honour considered that some works under the Contract required of Downer were “construction work” or supply of “related goods and services”, meaning the SOPA applied.  Relevantly, His Honour stated (accepting Downer’s counsel’s submission):

‘…if there is a contract which contains undertakings to carry out construction work and undertakings to carry out work that it not construction work, the contract remains a construction contract. If a payment claim includes a claim for work that is not construction work, the payment claim is valid, but the adjudicator should not award an amount for work that is not construction work. Thus, the Mining Exception has an important role to play in limiting the amount that the adjudicator should award.’[15]

On the reference date point, His Honour determined that there was an available reference date under the Contract for the service of the payment claim.  Most of the points raised were of limited significance for general application.  One point of general interest was that a clause of the Contract required Downer to invoice ‘in respect of the Services performed’ of the proceeding month.[16]  Downer’s works were performed not in the preceding month, but at an earlier time.

His Honour relied on s.13(4) of the SOPA which allows a contractor to serve a payment claim within the period determined under the construction contract or 12 months after construction work to which the claim relates was last carried out.  The payment clause in the Contract attempted to restrict the operation of s.13(4) and was a void provision, by operation of s.34 of the SOPA.

Take Home Tips

Contractors who consider that they are not entitled to have recourse to security of payment legislation simply because they work on a mine site should re-examine closely the terms of their contract.  Can it really be said that the contract works are for the “purpose of” extraction?  Or is there some distance between the works to be performed and the eventual act of extraction?

Perhaps there are portions or stages of works under the contract to which the Mining Exception would apply, but this would not necessarily mean that the entire contract is not a “construction contract” within the meaning of the security of payment legislation.

 

 

[1] Queensland, Victoria, South Australia, Tasmania and the Australian Capital Territory.  However, Western Australia is likely to shortly follow suit once the Building and Construction Industry (Security of Payment) Bill 2020 (WA) passes through Parliament.

[2] Section 5(2) of the Building and Construction Industry (Security of Payment) Act 1999 (NSW).

[3] Cadia Holdings Pty Ltd v Downer EDI Mining Pty Ltd [2020] NSWSC 1588 per Stevenson J.

[4] HM Hire Pty Limited v National Plant and Equipment Pty Ltd [2012] QSC 4 and Thiess Pty Ltd v Warren Brothers Earthmoving Pty Ltd [2012] QCA 276 (Thiess)

[5] At [133].

[6] At [92] and [93].

[7] At [3].

[8] At [34].

[9] At [70].

[10] At [96], quoting Fryberg J in Thiess at [76].

[11] At [102]

[12] At [103] and [91].

[13] At [104].

[14] At [105].

[15] At [134].

[16] At [171].

Spring is here and so is the Building and Construction Industry Security of Payment Regulation 2020

/in

On 1 September 2020, the Building and Construction Industry Security of Payment Regulation 2020 commenced (2020 Regulation) repealing the 2008 Regulation.

The 2020 Regulation will provide the legislative support and administrative detail for the operation of the Building and Construction Industry Security of Payment Act 1999 (NSW) (Act) as provided by the amendments which commenced on 21 October 2019. These amendments came about to address poor payment practices and the high incidence of insolvencies in the building and construction industry and also, to facilitate prompt payment, preserve cash flow and resolve disputes quickly and efficiently.

The 2020 Regulation is not retrospective and will not apply to contracts entered into prior to its commencement date.

Key reforms of the 2020 Regulation include:

  • removing the annual reporting requirements for trust accounts to NSW Fair Trading,
  • introducing a requirement for head contractors to keep a ledger for retention money held in relation to each subcontractor and provide the subcontractor with a copy of a ledger at least once every 3 months or longer period of 6 months if agreed in writing, and also to provide trust account records to subcontractors if their money is held in trust,
  • supporting statements are only required for subcontractors or suppliers directly engaged by the head contractor,
  • removing owner occupier construction contracts as a prescribed class of construction contract to which the Act does not apply, and
  • introducing qualifications and eligibility requirements for adjudicators to improve the quality of adjudication determinations under the Act.  The eligibility requirements include either a degree or diploma in a relevant specified field with at least 5 years’ experience, or at least 10 years’ experience in a relevant specified field.  The continuing professional development requirements for adjudicators will commence on 1 September 2021.

Of particular note, the project value threshold (value of the head contractor’s contract with the principal) for retention money trust account requirements will not be reduced from $20 million to $10 million as previously foreshadowed. The existing threshold will remain. Perhaps, given the current climate, it was considered too much of an administrative burden on head contractors who are already dealing with the pressures of delivering projects during Covid. A copy of the 2020 Regulation is  here.

If you would like to discuss or would like any more information, please contact us at [email protected] or (02) 9248 3450.

If you would like to receive our regular newsletters, please click  here.

ADR Processes

/in

 

ADR Processes: What are they and how do they work?

 

In many construction contracts, it is common to have a clause that deals with the process the parties will go through if a dispute arises. These clauses attempt to provide an alternative dispute resolution (ADR) process to litigating over every dispute that arises. While there are some disputes that are suited to being litigated (such as where a specific legal remedy is needed, the subject matter involves the legal rights of the parties or the issues are legally complex), many can be resolved through an ADR processes. ADR processes, if effective, can reduce the time and cost of disputes for parties.

 

This article discusses the different types of ADR processes and Part II will address some of the common pitfalls of ADR clauses that render these clauses unenforceable.

 

Types of ADR processes:

 

When it comes to construction disputes, there are several standard types of ADR processes. These include:

 

  • Negotiations between senior executives or authorised representatives;
  • Mediation;
  • Arbitration; and
  • Expert determination and appraisal.

 

Negotiations

 

Negotiation between senior executives is the most simple and informal dispute resolution process. The senior executives or authorised representatives meet and discuss the dispute that has arisen. Using their best endeavours, the authorised representatives can talk about how the dispute may be resolved and attempt and find any potential compromises. While the discussions may not necessarily resolve the dispute, it gives the parties a chance to hear the other side and understand the issues faced by the other party. This can help narrow the issues that are in dispute between the parties, saving significant time and money if the dispute escalates to litigation.

 

Mediation

 

The next step in the ADR ladder is mediation. Mediation is slightly more formal than negotiations between the parties’ authorised or senior representatives. This is because mediation involves appointing a third party (the mediator) to meet with the parties and work to resolve the dispute. The mediator will discuss the positions and interests of each party and try to find common ground on which the parties can agree and tries to help facilitate a resolution of the dispute.

 

One of the biggest benefits of mediation is the fact that it is so flexible in the resolutions that can be generated in response to a dispute. For instance, parties can find creative or unorthodox solutions to their problems which would not be available if the dispute were to be litigated. At mediation, the parties have the control over the resolution of the dispute and can work together to create a solution that is potentially more appropriate than a court order.

Arbitration

 

Arbitration is a common dispute resolution process in the building industry. Between commercial parties, arbitration can be an effective alternative to court because it operates much like a Court. The Commercial Arbitration Act 2010 (NSW) sets out the various matters relating to domestic commercial arbitrations including the arbitrator’s powers and the appeal process. The decisions of arbitrators are binding and the resulting awards can be enforced by the Courts.

 

Arbitrations can sometimes be as expensive and time consuming as litigation. This is because of several factors such as the cost of hiring an arbitrator and decisions are often appealed. However, some of the benefits of choosing arbitration include that it can be confidential and allows the parties to have more control over the rules and procedures that resolve the dispute. Subject to any overriding arbitration legislation or rules, the parties can essentially decide how they want the determination to run, how many arbitrators they want involved or any grounds of appeal.

 

Expert Determination

 

Another ADR process discussed in this article is expert determination. Expert determination can be binding, or non-binding (dependent on the rules of the particular expert agreement or contract that sends the parties in dispute into that forum). Unlike arbitration, there is no statutory framework for expert determination or appraisal. Therefore, it is the contract that will guide the expert and their decision. Using an expert to make a final and binding decision is useful, as the majority (if not all) building disputes will rely on expert evidence to determine issues such as program, defects or rectification costs.

 

Using non-binding expert determination can prevent or reduce the need for a court to consider these technical issues and can simplify the litigation process. A potential drawback for expert determination is that it can be very difficult to challenge. Provided the expert has understood the scope of their obligations and the issues they need to review, it often will not matter if the expert made a mistake, a gross over or under valuing or if irrelevant considerations were considered. As stated by the NSW Supreme Court in TX Australia Pty Limited v Broadcast Australia Pty Limited [2012], the fundamental question is whether the exercise performed by the expert in fact satisfies the terms of the contract.

 

It is not uncommon for a dispute resolution clause to have multiple different ADR processes available to the parties. For example, parties may be required to enter negotiations with each other and then must proceed to mediation or arbitration. Therefore, it is important to understand the aspects of each different ADR process so that you can choose the one most appropriate for your business. Each ADR process has its benefits and its drawbacks and will be more effective for certain types of disputes. In the Part II of this article, we will look at dome of the common pitfalls of ADR clauses. Particularly, how you ensure that the clause is enforceable, the key aspects of the ADR clause, and what are the common issues that arise when negotiating an ADR clause.